Laserfiche WebLink
in California, with expertise in hazardous waste site <br /> cleanup. Respondent ' s contractor or consultant shall have <br /> the technical expertise sufficient to fulfill his or her <br /> responsibilities . Within fourteen (14) days of the <br /> effective date of this Consent Agreement, Respondent shall <br /> notify DTSC Project Coordinator in writing of the name, <br /> title, and qualifications of the professional engineer or <br /> registered geologist and of any contractors or consultants <br /> and their personnel to be used in carrying out the terms of <br /> this Consent Agreement . DISC may disapprove of <br /> Respondent ' s contractor and/or consultant . <br /> QUALITY ASSURANCE <br /> 10 . 1 . All sampling and analyses performed by <br /> Respondent under this Consent Agreement shall follow <br /> applicable DISC and USEPA guidance for sampling and <br /> analysis . workplans shall contain quality <br /> assurance/quality control and chain of custody procedures <br /> for all sampling, monitoring, and analytical activities. <br /> Any deviations from the approved workplans must be approved <br /> by DTSC prior to implementation, must be documented, <br /> including reasons for the deviations, and must be reported <br /> in the applicable report (e .g. , FI Report) . <br /> 10 . 2 . The names, addresses, and telephone numbers of <br /> the California State certified analytical laboratories <br /> Respondent proposes to use must be specified in the <br /> applicable workplans . <br /> SAMPLING AND DATA/DOCUMENT AVAILABILITY <br /> 11 . 1 . Respondent shall submit to DTSC upon request <br /> the results of all sampling and/or tests or other data <br /> generated by its employees, agents, consultants, or <br /> contractors pursuant to this Consent Agreement . <br /> 11 . 2 . Respondent shall notify DTSC in writing at <br /> least seven (7) days prior to beginning each separate phase <br /> of field work approved under any workplan required by this <br /> Consent Agreement . If Respondent believes it must commence <br /> emergency field activities without delay, Respondent may <br /> seek emergency telephone authorization from DTSC Project <br /> Coordinator or, if the Project Coordinator is unavailable, <br /> 6 <br />