COMPLIANCE INFO_FILE 2 - Laserfiche WebLink

Home Browse Search

REPRODUCED AT GOVERNMENT EXPENSE, details of the work but they shall be performed as if fully and correctly Set forth and described in the drawings and specifications. (FAR SUPP 52-326-7002(b)) 1.2.1.3 The Contractor shall check all drawings furnished him immediately upon their receipt and shall promptly notify the Contracting officer of any discrepancies. Figures marked on drawings shall in general be followed in preference to scale measurements. Large scale drawings shall in general govern small scale drawings. The Contractor shall compare all drawings and verify the figures before laying out the work and will be responsible for any errors which might have been avoided thereby. (FAR suPP 52.326-7002(c)) 1.2.1.4 Number of Sets Furnished: In addition to the reproducible set of drawings and specifications furnished in accordance with FAR Supplement 52.236-7002, the Contracting officer will furnish up to 10 sets of full-size drawings and 10 copies of the contract specifications without charge, after award of the contract. 1.2.1.5 Reference Drawings: As -Built Utility Drawings not specified or indicated on the attached sketches are available at the Public Works office for prospective bidders. 1.3 INFORMATION REQUIRED OF THE CONTRACTOR: 1.3.1 Subcontractors and Personnel: Provide a list of key personnel of the Contractor and subcontractors (including addresses and telephone numbers) for use in the event of an emergency. As changes occur and additional information becomes available, correct and change the information contained in previous lists. 1.3.2.1 Construction Schedule: Within 15 days after issuance of a Delivery Order, the Contractor shall submit a closure plan for the work described in this contract. Submit for approval, in the format prescribed by the Contracting officer, and include as a minimum the following information: a. The various classes and areas of work, broken down into: (1) Times projected for submittals, approvals, and procurements. (2) Times for tank emptying, degassing, excavation, cleaning, disposal, tank hauling and site closure and finishing. (3) Times for testing and inspection. b. Identify all critical items of work which will delay the start or completion of other major items of work so as to delay completion off the whole project. c. The work completed and the work remaining to be done to complete the project.