Laserfiche WebLink
9.5. Unless otherwise specified, all reports, correspondence, approvals, <br /> disapprovals, notices, or other submissions relating to this Consent Agreement shall be <br /> in writing and shall be sent to the current Project Coordinators. <br /> PROPOSED CONTRACTOR/CONSULTANT <br /> 10. All work performed pursuant to this Consent Agreement shall be under the <br /> direction and supervision of a professional engineer or registered geologist, registered <br /> in California, with expertise in hazardous waste site cleanup. Respondent's contractor <br /> or consultant shall have the technical expertise sufficient to fulfill his or her <br /> responsibilities. Within 14 days of the effective date of this Consent Agreement, <br /> Respondent shall notify DTSC Project Coordinator in writing of the name, title, and <br /> qualifications of the professional engineer or registered geologist and of any contractors <br /> or consultants and their personnel to be used in carrying out the terms of this Consent <br /> Agreement. <br /> QUALITY ASSURANCE <br /> 11.1. All sampling and analyses performed by Respondent under this Consent <br /> Agreement shall follow applicable DTSC and USEPA guidance for sampling and <br /> analysis. Workplans shall contain quality assurance/quality control and chain of custody <br /> procedures for all sampling, monitoring, and analytical activities. Any deviations from <br /> the approved workplans must be approved by DTSC prior to implementation, must be <br /> documented, including reasons for the deviations, and must be reported in the <br /> applicable report. <br /> 11.2. The names, addresses, and telephone numbers of the California State <br /> certified analytical laboratories Respondent proposes to use must be specified in the <br /> applicable workplans. <br /> SAMPLING AND DATA/DOCUMENT AVAILABILITY <br /> 12.1. Respondent shall submit to DTSC upon request the results of all sampling <br /> and/or tests or other data generated by its employees, agents, consultants, or <br /> contractors pursuant to this Consent Agreement. <br /> 12.2. Respondent shall notify DTSC in writing at least seven days prior to <br /> beginning each separate phase of field work approved under any workplan required by <br /> this Consent Agreement. If Respondent believes it must commence emergency field <br /> activities without delay, Respondent may seek emergency telephone authorization from <br /> DTSC Project Coordinator or, if the Project Coordinator is unavailable, his/her Unit <br /> Chief, to commence such activities immediately. <br /> 12.3. At the request of DTSC, Respondent shall provide or allow DTSC or its <br /> authorized representative to take split or duplicate samples of all samples collected by <br /> Respondent pursuant to this Consent Agreement. Similarly, at the request of <br /> 7 <br />